Welcome to abdulqadeer.click (“the Website”), owned and operated by Abdul Qadeer (“I”, “me”, “my”, “the Consultant”), a digital solutions consultant providing web development, digital marketing, conversion optimisation, AI automation, and business development services, primarily to gyms, clinics, and wellness businesses in the United Kingdom and internationally.
By accessing this Website, booking a strategy call, or engaging my services, you (“the Client”, “you”, “your”) agree to be bound by these Terms and Conditions. Please read them carefully before using the Website or engaging any services. If you do not agree with any part of these terms, please do not use the Website or engage my services.
1. About These Terms
These Terms and Conditions govern:
- Your use of this Website and its content
- Any consultation, project, retainer, or service booked or purchased through this Website, email, WhatsApp, or any other communication channel
- The relationship between you and me as an independent consultant
Separate written agreements, proposals, or Statements of Work (“SOW”) issued for individual projects may include additional or more specific terms. Where a conflict arises between a signed SOW/proposal and these general Terms, the SOW/proposal will take precedence for that engagement.
2. Services
I provide digital consulting services including, but not limited to:
- Website design and development (WordPress, Shopify, custom builds)
- Digital marketing strategy, SEO, AEO/GEO, paid advertising (Google Ads, Meta Ads), and local SEO
- Conversion rate optimisation, UX and funnel audits
- AI automation and workflow implementation (e.g. Make.com, Zapier, chatbots)
- Business development and e-commerce/SaaS strategy advisory
The exact scope, deliverables, timeline, and price of each engagement will be confirmed separately, typically following a free strategy call, in a written quote, proposal, or SOW. Nothing on this Website constitutes a binding offer of specific services or pricing; published prices (e.g. “from £799”) are indicative starting points and the final price depends on scope.
3. Free Strategy Calls & Enquiries
Free strategy calls are offered to assess whether my services are a good fit for your business. Booking a call does not obligate either party to proceed with paid work. I reserve the right to decline any project at my discretion, including after a strategy call.
4. Quotes, Proposals & Engagement
- A project only begins once a proposal, quote, or SOW has been agreed in writing (including via email) and, where applicable, any required deposit has been received.
- Quotes are valid for 14 days from the date issued unless otherwise stated.
- Any changes to the agreed scope after work has started may be treated as a change request and may incur additional fees and/or affect the delivery timeline (see Section 7).
5. Fees & Payment
- Fees are quoted in GBP (£) unless otherwise agreed, and are exclusive of any applicable taxes unless stated otherwise.
- For project-based work (e.g. website builds), a non-refundable deposit (typically 50%) is required before work begins, with the balance due on completion or per the milestones set out in the proposal, prior to final handover/publishing of deliverables.
- For retainer-based services (e.g. monthly SEO or marketing management), fees are billed monthly in advance and are due on the agreed billing date. Retainers renew automatically each month unless cancelled in accordance with Section 9.
- Invoices not paid within the agreed terms (typically 7 days of the due date) may result in suspension of work or services until payment is received. Late payments may incur a reasonable administrative fee.
- Payment can be made via the methods specified on the invoice (e.g. bank transfer, card payment).
- Third-party costs (e.g. hosting, domain registration, premium plugins/themes, ad spend, software subscriptions) are separate from my fees unless explicitly included in the proposal, and are payable directly by the Client or reimbursed to me as agreed.
6. Client Responsibilities
To deliver services effectively and on time, the Client agrees to:
- Provide timely access to necessary accounts, content, branding assets, credentials, and information
- Provide feedback and approvals within a reasonable time (typically 3–5 business days unless otherwise agreed)
- Ensure all content, images, testimonials, and materials supplied to me are accurate, and that the Client holds the necessary rights/licences to use them
- Designate a single point of contact for approvals and feedback where possible
Delays caused by the Client in providing information, feedback, or access may extend project timelines accordingly, and I am not responsible for delays resulting from Client-side delays.
7. Revisions & Change Requests
- Each project includes a reasonable number of revision rounds as specified in the proposal.
- Requests that go beyond the agreed scope, or that are made after a milestone has been signed off, may be treated as additional work and quoted separately.
- I aim to respond to revision requests within a reasonable timeframe but cannot guarantee specific turnaround times unless agreed in writing.
8. Project Timelines
Estimated timelines are provided in good faith based on the agreed scope and timely Client cooperation. Timelines are not guaranteed and may be affected by factors including but not limited to: scope changes, delayed feedback, third-party platform issues, or circumstances beyond my reasonable control (see Section 15, Force Majeure).
9. Cancellations & Refunds
- Project-based work: Deposits are non-refundable once work has commenced, as they cover time, planning, and resource allocation already committed. If a project is cancelled by the Client after work has started, any additional fees for work completed up to the point of cancellation will be invoiced and are payable.
- Retainers: Monthly retainer services may be cancelled by either party with a minimum of 14 days’ written notice before the next billing date. Fees already paid for the current billing period are non-refundable, but no further payments will be taken after cancellation takes effect.
- My right to cancel: I reserve the right to terminate an engagement with written notice if payment is not received, if the Client is uncooperative in a way that makes delivery impossible, or if either party breaches these Terms materially and fails to remedy the breach within a reasonable period after notice.
- Refunds, where applicable, will be assessed on a case-by-case basis and are at my discretion unless otherwise required by law.
10. Intellectual Property
- Upon receipt of full payment, ownership of custom deliverables created specifically for the Client (e.g. final website files, custom graphics created for the project) transfers to the Client, unless otherwise agreed in writing.
- I retain the right to use pre-existing tools, frameworks, code snippets, processes, and general know-how developed prior to or independently of the engagement.
- Third-party assets (themes, plugins, stock images, fonts, software, platforms such as WordPress, Shopify, Make.com, Zapier) remain subject to their own licences, and the Client is responsible for any ongoing licence fees required to continue using them.
- Unless the Client opts out in writing, I may reference completed projects (excluding confidential information) in my portfolio, case studies, and marketing materials, including testimonials provided by the Client.
- Until full payment has been received, I retain all rights to the work produced and it may not be used, published, or distributed by the Client.
11. Confidentiality
Both parties agree to keep confidential any non-public business, technical, or financial information disclosed during the engagement, and not to disclose it to third parties, except: (a) where required by law, or (b) where the information becomes publicly available through no fault of the receiving party. This obligation survives the end of the engagement.
12. No Guaranteed Results
Digital marketing, SEO, advertising, and automation outcomes (such as rankings, traffic, leads, sales, or conversions) depend on numerous factors outside my control, including search engine algorithm changes, market conditions, competitor activity, ad platform policies, and Client-side execution. While I apply industry best practices and my professional experience to every engagement, I do not guarantee specific results, rankings, revenue, or timeframes, and no such guarantee should be inferred from the Website, proposals, case studies, or testimonials.
13. Third-Party Platforms & Services
Services may involve the use of third-party platforms (e.g. WordPress, Shopify, Google, Meta, Make.com, Zapier, hosting providers, payment processors). I am not responsible for outages, policy changes, price changes, data loss, or account suspensions caused by these third parties, though I will act reasonably to assist the Client in resolving such issues where possible.
14. Limitation of Liability
- To the fullest extent permitted by law, my total liability arising out of or in connection with any engagement (whether in contract, tort, or otherwise) shall not exceed the total fees paid by the Client for the specific service giving rise to the claim in the preceding 3 months.
- I am not liable for indirect, incidental, or consequential losses, including but not limited to loss of profits, loss of business opportunity, or loss of data, except where such liability cannot be excluded by law.
- Nothing in these Terms limits or excludes liability for death or personal injury caused by negligence, fraud, or any other liability that cannot be limited or excluded under applicable law.
15. Force Majeure
Neither party will be liable for delays or failure to perform obligations due to causes beyond their reasonable control, including but not limited to natural disasters, internet or platform outages, power failures, acts of government, or other unforeseeable events.
16. Website Use
- Content on this Website (text, graphics, logos, images) is owned by me or licensed for use, and may not be copied, reproduced, or distributed without prior written permission, except for personal, non-commercial reference.
- I make reasonable efforts to keep Website content accurate and up to date but do not warrant that all information is complete, current, or error-free.
- Blog and educational content on this Website is provided for general informational purposes only and does not constitute professional advice specific to your business.
17. Communication
Project communication may take place via email, WhatsApp, phone/video call, or other agreed channels. Response times are handled on a reasonable-efforts basis during normal business hours, and no specific SLA (service level agreement) applies unless separately agreed in writing.
18. Independent Contractor Relationship
I operate as an independent consultant/contractor. Nothing in these Terms creates a partnership, joint venture, agency, or employment relationship between the Client and me.
19. Changes to These Terms
I may update these Terms and Conditions from time to time to reflect changes in my services or for legal/regulatory reasons. The updated version will be posted on this page with a revised “Last Updated” date. Continued use of the Website or ongoing services after changes are posted constitutes acceptance of the revised Terms. Material changes affecting an active, signed engagement will not be applied retroactively without agreement.
20. Governing Law & Jurisdiction
These Terms and Conditions are governed by and construed in accordance with the laws of England and Wales. Any disputes arising out of or in connection with these Terms or any engagement shall be subject to the exclusive jurisdiction of the courts of England and Wales, unless otherwise required by applicable local consumer protection law.
21. Severability
If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions will continue in full force and effect.
22. Contact
If you have any questions about these Terms and Conditions, please get in touch:
- Email: hello@abdulqadeer.click
- WhatsApp: +92 312 766 1035
- LinkedIn: linkedin.com/in/abdulqadeerr
- Website: abdulqadeer.click